Centrifugal Pump Repair and Modification

|4|N7M1.5|HFB|7176052828|[email protected]| ITEM UNIQUE IDENTIFICATION AND VALUATION (MAR 2022)|19|||||||||||||||||||| INSPECTION OF SUPPLIES--FIXED-PRICE (AUG 1996)|2||| WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (DEC 2018)|16|COMBO||TBD|N00104|TBD|TBD|SEE SCHEDULE|SEE SCHEDULE|SEE SCHEDULE||TBD|||||| NAVY USE OF ABILITYONE SUPPORT CONTRACTOR - RELEASE OF OFFEROR INFORMATION (3-18))|1|WSS| EQUAL OPPORTUNITY (SEP 2016)|2||| BUY AMERICAN --FREE TRADE AGREEMENTS--BALANCE OF PAYMENTS PROGRAM - BASIC(DEVIATION 2020-O0019) (MAR 2022))|3|||| ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (NOV 2020)|13|||||||||||||| BUY AMERICAN-FREE TRADE AGREEMENTS-BALANCE OF PAYMENTS PROGRAM CERTIFICATE (DEVIATION 2020-O0019) (JUL 2020))|3|||| BUY AMERICAN-BALANCE OF PAYMENTS PROGRAM CERTIFICATE-BASIC (NOV 2014)|1|| ANNUAL REPRESENTATIONS AND CERTIFICATIONS (JAN 2022)|13|333914|750|||||||||||| NOTICE OF PRIORITY RATING FOR NATIONAL DEFENSE, EMERGENCY PERPARDENESS, AND ENRGY PROGAM USE (APRIL 2008))|2||X|

EVALUATION CRITERIA AND BASIS FOR AWARD-|1|| This amendment reflects an increase in QTY, change of POC, and extension of quote due date. All other information is the same. Accelerated delivery is encouraged and accepted before the delivery date(s) listed in the schedule. ^^ All freight is FOB Origin. This RFQ is for repair. The resultant award of this solicitation will be issued bilaterally, requiring the contractors written acceptance prior to execution.. Verify nomenclature, part number, and NSN prior to responding. The Government is seeking a Repair Turnaround Time (RTAT) of: 190 DAYS Government Source Inspection (GSI) is required. Please note freight is handled by Navy CAV or Proxy CAV as stated in NAVSUPWSSFA24 or NAVSUPWSSFA25. Your quote should include the following information: QUOTE AMOUNT AND RTAT Unit Price:__________ Total Price:__________ Repair Turnaround Time (RTAT): _______ days Check one: Firm-fixed-Price ___ Not to Exceed (Ceiling Price) ___ Estimated ___ Return Material Authorization # (RMA), if applicable:__________ Delivery Vehicle (if Delivery Order requested) (if your company has a current BOA/IDIQ, for example) :__________________ TESTING AND EVALUATION IF BEYOND REPAIR T&E fee/price (if asset is determined BR/BER): If an item is determined BR, and the contractor provides documentation that costs were incurred during evaluation and determination of BR, the

contracting officer will negotiate a reduced contract price, not-to exceed (NTE) $___________associated with the repair effort to reflect the BR status of the equipment. The T&E fee (if asset is determined BR/BER) was determined/computed based on:______________________________________. AWARDEE INFO & PERFORMANCE LOCATION Awardee CAGE: __________ Inspection & Acceptance CAGE, if not same as "awardee CAGE": __________ Facility/Subcontractor CAGE (where the asset should be shipped), if not same as "awardee CAGE":__________ IOT COMPARE REPAIR PRICE TO PRICE TO BUY NEW New unit price:__________ New unit delivery lead-time:__________ IMPORTANT NOTE: Any asset for which the contractor does not meet the required RTAT will incur a price reduction per unit/per month the contractor is late - any delay determined to be excusable (e.g. Government Delay) will not result in a price reduction. If a price reduction is required due to unexcusable contractor delay, the

Contracting Officer will implement the aforementioned price reduction via a "reconciliation modification" at the end of the contract performance. Price reductions made pursuant to this section shall not limit other remedies available to the Government for failure to meet required RTATs, including but not limited to the Government's right to terminate for default. In reference to the above important note, the contractor provides the following price reduction amount per unit per month the contractor does not meet the RTAT: $__________, up to a maximum of: $_________. \ 1. SCOPE 1.1 This contract/purchase order contains the

requirements for repair and the contract quality

requirements for the PUMP,CENTRIFUGAL . 2. APPLICABLE DOCUMENTS 2.1 Applicable Documents - The document(s) listed below form a part of this contract/purchase order including modifications or exclusions. 2.1.1 "Document References" listed below must be obtained by the Contractor. Ordering information is included as an attachment to this contract/purchase order. 3.