Solenoid Valve Supply and Installation

|4|N713.36|GLJ|771-229-0926|[email protected]| ITEM UNIQUE IDENTIFICATION AND VALUATION (JAN 2023)|19|||||||||||||||||||| INSPECTION OF SUPPLIES--FIXED-PRICE (AUG 1996)|2||| WIDE AREA WORKFLOW PAYMENT INSTRUCTIONS (JAN 2023)|16|COMBO - INVOICE AND RECEIVING REPORT||TBD|N00104|TBD|TBD|SEE SCHEDULE|TBD|||TBD|||||| NAVY USE OF ABILITYONE SUPPORT CONTRACTOR - RELEASE OF OFFEROR INFORMATION (3-18))|1|WSS| MANDATORY USE OF WORKFLOW PRO (WFP) MOD ASSIST MODULE|1|| BUY AMERICAN-FREE TRADE AGREEMENTS-BALANCE OF PAYMENTS PROGRAM-BASIC (FEB 2024)|11|||||||||||| SMALL BUSINESS SUBCONTRACTING PLAN (DOD CONTRACTS)-BASIC (DEV 2026-O0037)(FEB 2026))|2||| CONTRACTOR PURCHASING SYSTEM ADMINISTRATION-BASIC (DEVIATION 2026-O0015)|1|| SECURITY PROHIBITIONS AND EXCLUSIONS (CLASS DEVIATION 2026-O0025)(FEB 2026)|7|||||||| BUY AMERICAN-FREE TRADE AGREEMENTS-BALANCE OF PAYMENTS PROGRAM CERTIFICATE-BASIC (FEB 2024))|5|||||| BUY AMERICAN-BALANCE OF PAYMENTS PROGRAM CERTIFICATE-BASIC (FEB 2024)|1|| ALTERNATE A, ANNUAL REPRESENTATIONS AND CERTIFICATIONS (DEVIATION 2026-O0043)(FEB 2026))|13|||||||||||||| NOTICE OF PRIORITY RATING FOR NATIONAL DEFENSE, EMERGENCY PERPARDENESS, AND ENRGY PROGAM USE (APRIL 2008))|2||| Accelerated delivery is encouraged and accepted before the delivery date(s) listed in the schedule. ^^ "All freight is FOB Origin. This RFQ is for a buy. The resultant award of this solicitation will be issued bilaterally, requiring the contractor?s written acceptance prior to execution. Verify nomenclature, part number, and NSN prior to responding. Government source inspection is required. Unit Price:__________ FIRM Total Price:__________ FIRM Procurement Turnaround Time (PTAT) :__________ Awardee CAGE: __________ Inspection & Acceptance CAGE, if not at source:__________ Delivery Vehicle (if Delivery Order requested) (if your company has a current BOA/IDIQ, for example) :__________ Important Traceability Notice: If you are not the manufacturer of the material you are offering, you must provide a letter/official email from the OEM confirming your company is an authorized distributor of their items. IMPORTANT NOTE: Any asset for which the contractor does not meet the required RTAT will incur a price reduction per unit/per month the contractor is late - any delay determined to be excusable (e.g. Government Delay) will not result in a price reduction. If a price reduction is required due to unexcusable contractor delay, the

Contracting Officer will implement the aforementioned price reduction via a ""reconciliation modification"" at the end of the contract performance. Price reductions made pursuant to this section shall not limit other remedies available to the Government for failure to meet required RTATs, including but not limited to the Government's right to terminate for default. In reference to the above important note, the contractor provides the following price reduction amount per unit per month the contractor does not meet the RTAT: $__________, up to a maximum of: $_________. \ 1. SCOPE 1.1 This contract/purchase order contains the

requirements for manufacture and the contract quality

requirements for the VALVE,SOLENOID . 2. APPLICABLE DOCUMENTS 2.1 Applicable Documents - The document(s) listed below form a part of this contract/purchase order including modifications or exclusions. 2.1.1 "Document References" listed below must be obtained by the Contractor. Ordering information is included as an attachment to this contract/purchase order. 3.

REQUIREMENTS 3.1 Cage Code/Reference Number Items - The VALVE,SOLENOID furnished under this contract/purchase order shall be the design represented by Cage Code(s) reference number(s). Cage _______ ref. no. ;62144 13100-58; 3.2 Marking - This item shall be physically identified in accordance with ;MIL-STD-130, REV N,

16 NOV 2012; . 3.3 Changes in Design, Material Servicing, or Part Number - Except for a Code 1 change, which shall be processed as provided in the code statement shown below, no substitution of items shall be made until the NAVICP-MECH